top of page
_edited.png)
Delay attributable to employer disentitles imposition of liquidated damages: Delhi high court upholds arbitral award in favour of NH road contractor
Delhi High Court Supports NH Road Contractor: Employer-Caused Delays Prevent Liquidated Damages. Case Title: Public Works Department, NH Wing and Anr. v. GVR Infra Projects Ltd. Case Number: O.M.P. (COMM) 236/2026 | Delhi High Court | Justice Subramonium Prasad The Delhi High Court has dismissed a petition filed under Section 34 of the Arbitration and Conciliation Act, 1996, upholding an arbitral award of over Rs. 48.57 crores passed in favour of a road construction contrac
bottom of page